Pennsylvania Department of Conservation and Natural Resources

Track open bid opportunities, contracts, public meetings, and key contacts for Pennsylvania Department of Conservation and Natural Resources.

Buyer type:: State Agency
Location:: Blain, PA
Country:: US

Pennsylvania Department of Conservation and Natural Resources RFPs

Active opportunities open for bidding

20-2026BC07 - Big Hollow Salvage RFP
Posted
Nov 5, 2026
Closes
Dec 30, 2026
Pennsylvania Department of Conservation and Natural Resources Bureau of Forestry is offering a timber harvest on approximately 30 acres in the Hillsgrove area of Plunketts Creek Township, spanning Sullivan and Lycoming counties. The sale includes about 146 MBF of primarily black-cherry sawtimber and 44 HCF of northern-hardwood pulpwood, with felling, extraction, and removal required. Bidders must submit a lump-sum bid with a $2,500 bid bond and meet FSC/SFI certification and seasonal restrictions; bids are due December 30, 2026 at noon EST, and bids below $28,410.44 will be rejected.
04-2026BC01 - Jones Mill Run RFP
Posted
-
Closes
Dec 9, 2026
The Pennsylvania Department of Conservation and Natural Resources is soliciting bids for a timber sale covering approximately 140 acres in Jefferson Township, Somerset County. The work includes harvesting sawtimber and pulpwood, constructing haul roads, installing culverts, delivering limestone, seeding, and complying with environmental requirements. Bids are due electronically by December 9, 2026, and require a $10,000 bid bond; a performance bond may also be required.
04-2026BC01 - Jones Mill Run
Posted
-
Closes
Dec 9, 2026
The Pennsylvania Department of Conservation and Natural Resources is soliciting bids for a timber sale covering approximately 140 acres in Jefferson Township, Somerset County. The work includes harvesting sawtimber and pulpwood, constructing haul roads, installing culverts, delivering limestone, seeding, and complying with environmental requirements. Bids are due electronically by December 9, 2026, and require a $10,000 bid bond; a performance bond may also be required.

View all RFPs

Buyer Attributes

Key metrics and characteristics

City
The city where this buyer is located.
Blain
County
The county where this buyer is located.
Perry
Address
Physical address of this buyer.
4455 Big Spring Rd
Zip Code
Postal code for this buyer's location.
17006
Propensity to Spend
How likely this buyer is to spend on new technology based on operating budget trends.
CautiousAggressive
Higher is better Unlock
AI Adoption Score
How likely this buyer is to adopt new AI technologies.
ConservativeEarly Adopter
Higher is better Unlock
Startup Friendliness
How often this buyer champions startups and early adoption.
TraditionalStartup-Friendly
Higher is better Unlock
Latest Budget Year
Unlock to view
Unlock
Operating Budget
Unlock to view
Unlock

Unlock full profile

Includes fiscal year calendars, procurement complexity scores, and strategic insights.

RFP Intelligence

Find best-fit RFPs — Then Nail the Response

Get alerted before the bid drops, know which RFPs to pursue, and generate compliant drafts with AI.

Book a demo

AI-ranked best-fit opportunities before bid boards

Auto-drafted, compliance-ready outlines & boilerplate

Competitor & pricing intel from past awards

How to Sell to Pennsylvania Department of Conservation and Natural Resources

Procurement guidance and navigation tips.

Suggested contract vehicles to explore for Pennsylvania Department of Conservation and Natural Resources

These are suggested options, not confirmed memberships or past purchases. Our team can help confirm the right purchasing path for this agency.

TIPS
OMNIA
Sourcewell

Check my procurement options

Pennsylvania Department of Conservation and Natural Resources Contracts

Track vendor wins and renewal opportunities

RTG Solutions at Pennsylvania Department of Conservation and Natural Resources
Effective: Oct 23, 2026Expires: Expiration date locked.
Hickes Associates Inc. at Pennsylvania Department of Conservation and Natural Resources
Effective: Sep 15, 2026Expires: Expiration date locked.
This Construction Contract outlines the agreement between the Commonwealth of Pennsylvania, Department of Conservation and Natural Resources (DEPARTMENT) and Bickes Associates Inc. (CONTRACTOR) for the rebuild/rehab of blowers at the sewage treatment plant at Canoe Creek State Park. The total contract amount is $357,389.98. The work is to be completed within 365 days of the official starting date, which is defined as the tenth day after receipt of a notice to start work. The contract also specifies payment terms, liquidated damages, bonds, compliance requirements, and dispute resolution processes.
S & S Electrical Services, Inc. at Pennsylvania Department of Conservation and Natural Resources
Effective: Jan 28, 2026Expires: Expiration date locked.
This document is Time Extension #1 for Contract No. FDC-400-10984.4R between S & S Electrical Services, Inc. and the Pennsylvania Department of Conservation and Natural Resources. It extends the completion date for electrical construction and dorm room renovations at Hickory Run State Park from an unspecified previous date to December 7, 2026, due to project delays beyond the contractor's control, such as asbestos abatement and structural issues. The extension is granted with the explicit condition that no additional costs or damages will be paid by the Department.
Caliber Contracting Services, Inc. at Pennsylvania Department of Conservation and Natural Resources
Effective: Jan 28, 2026Expires: Expiration date locked.
This document serves as Time Extension #1 for Contract No. FDC-400-10984.1, between the Pennsylvania Department of Conservation and Natural Resources (DCNR) and Caliber Contracting Services, Inc. for Dorm Room Renovations at Hickory Run State Park. The original agreement was dated January 28, 2026. Due to delays stemming from asbestos abatement, structural wood framing, site sanitary issues, and additional floor preparation/moisture mitigation, the contract completion date is extended to December 7, 2026. By accepting this extension, the contractor waives any claims for additional expenses or damages incurred due to the delay.
Bognet, Inc. at Pennsylvania Department of Conservation and Natural Resources
Effective: Feb 5, 2026Expires: Expiration date locked.
This document is a contract extension (Time Extension #1) for Contract No. FDC-400-10984.3 between DCNR (Pennsylvania Department of Conservation and Natural Resources) and Bognet, Inc. for plumbing construction and dorm room renovations at Hickory Run State Park. The extension is granted due to unforeseen site conditions such as asbestos, structural issues, and moisture mitigation. The original agreement commenced on February 5, 2026, and the completion date is now extended to December 7, 2026. The contractor waives any claims for additional expenses or damages incurred due to this time extension.

Early Buyer Signals

Board meetings and strategic plans from Pennsylvania Department of Conservation and Natural Resources

Conservation and Natural Resources Advisory Council Meeting
Date: Sep 23, 2026Type: Meeting mention
The Council meeting covered several administrative and policy topics, including a tribute to the legacy of former state senator Franklin Curry and his role in the Environmental Rights Amendment. Key agenda items included the introduction of a new Council logo designed to meet ADA accessibility standards, and a preview of upcoming webinars concerning e-bike policy management and trending recreation uses. The meeting also addressed inquiries from the public regarding forest management practices and provided updates on the economic growth of Pennsylvania's outdoor recreation sector.
Conservation and Natural Resources Advisory Council Council Meeting
Date: Jul 22, 2026Type: Meeting mention
The Council discussed the new special use permitting process implemented by the Department of Conservation and Natural Resources, highlighting concerns regarding administrative burdens and transparency while proposing improvements for recurring events. Updates were provided on the Council's updated rules of procedure, which aim to align officer terms with the calendar year. Economic development reports included the launch of the Pennsylvania Trout Tank Grant Program for outdoor businesses. Additionally, the Council received updates from the park and forest infrastructure group and acknowledged a leadership transition within the recreation working group.

Key Contacts

Public-sector contacts connected to Pennsylvania Department of Conservation and Natural Resources.

Sarah ChapelAdministrative Officer

*******@************

+1 (***) ***-****

Kathleen ChadwickAdministrative Services Section

Get relevant Pennsylvania Department of Conservation and Natural Resources bid alerts

Track Pennsylvania Department of Conservation and Natural Resources bids, renewals, public meetings, and contact changes matched to what you sell.

Product-relevant RFPs and bids
Contract renewal signals
Budget and meeting signals
Key contact updates

Track this buyer

Pennsylvania Department of Conservation and Natural Resources

Pennsylvania Department of Conservation and Natural Resources RFPs

Buyer Attributes

Find best-fit RFPs — Then Nail the Response

How to Sell to Pennsylvania Department of Conservation and Natural Resources

Suggested contract vehicles to explore for Pennsylvania Department of Conservation and Natural Resources

Pennsylvania Department of Conservation and Natural Resources Contracts

RTG Solutions at Pennsylvania Department of Conservation and Natural Resources

Hickes Associates Inc. at Pennsylvania Department of Conservation and Natural Resources

S & S Electrical Services, Inc. at Pennsylvania Department of Conservation and Natural Resources

Caliber Contracting Services, Inc. at Pennsylvania Department of Conservation and Natural Resources

Bognet, Inc. at Pennsylvania Department of Conservation and Natural Resources

Early Buyer Signals

Conservation and Natural Resources Advisory Council Meeting

Conservation and Natural Resources Advisory Council Council Meeting

Key Contacts

Get your 10 highest-intent accounts

Pennsylvania Department of Conservation and Natural Resources RFPs

Buyer Attributes

Find best-fit RFPs — Then Nail the Response

How to Sell to Pennsylvania Department of Conservation and Natural Resources

Suggested contract vehicles to explore for Pennsylvania Department of Conservation and Natural Resources

Pennsylvania Department of Conservation and Natural Resources Contracts

RTG Solutions at Pennsylvania Department of Conservation and Natural Resources

Hickes Associates Inc. at Pennsylvania Department of Conservation and Natural Resources

S & S Electrical Services, Inc. at Pennsylvania Department of Conservation and Natural Resources

Caliber Contracting Services, Inc. at Pennsylvania Department of Conservation and Natural Resources

Bognet, Inc. at Pennsylvania Department of Conservation and Natural Resources

Early Buyer Signals

Conservation and Natural Resources Advisory Council Meeting

Conservation and Natural Resources Advisory Council Council Meeting

Key Contacts

Get full contract and spend data

Pennsylvania Department of Conservation And Natural Resources Outdoor Recreation Plan Webinar

Know what buyers discuss before RFPs drop

Similar government buyers you might want to track